(1176,1,'2025-09-03 15:44:30',9,NULL,3063,'INV-',2,'INV-2025/003063','2025-09-03 14:54:49','2025-09-03',NULL,3,693.00,69.30,762.30,0.00,2,'0d8903669240e8921bdd419cb5f85528',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1177,1,'2025-09-03 15:44:48',9,NULL,3064,'INV-',2,'INV-2025/003064','2025-09-03 14:59:10','2025-09-03',NULL,3,753.04,75.30,828.34,0.00,2,'2c816c7159777e7c6bbf356b729b2f07',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1178,1,'2025-09-03 15:45:15',9,NULL,3065,'INV-',2,'INV-2025/003065','2025-09-03 15:01:42','2025-09-03',NULL,3,1435.61,143.56,1579.17,0.00,2,'77b50d01de15550d49fedd7423460cce',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1179,1,'2025-09-03 15:45:32',9,NULL,3066,'INV-',2,'INV-2025/003066','2025-09-03 15:08:31','2025-09-03',NULL,3,720.00,72.00,792.00,0.00,2,'a5811b9aa758661d64f5295b71622469',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1180,1,'2025-09-15 10:59:44',9,NULL,3060,'INV-',2,'INV-2025/003060','2025-09-03 15:13:20','2025-09-03',NULL,3,8964.00,896.40,9860.40,0.00,2,'9d4564ef219651972ad9bd6773dfa553',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1181,1,'2025-09-03 15:46:05',9,NULL,3067,'INV-',2,'INV-2025/003067','2025-09-03 15:16:26','2025-09-03',NULL,3,5670.00,567.00,6237.00,0.00,2,'26cacd3f28f6e2f4fb3f945ea34e648d',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1182,1,'2025-09-08 15:03:34',112,NULL,3074,'INV-',2,'INV-2025/003074','2025-09-08 14:19:09','2025-09-08',NULL,3,790.00,79.00,869.00,0.00,2,'5e11f0f677a96b407500239c51fbbf95',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1183,1,'2025-09-08 15:03:13',112,NULL,3073,'INV-',2,'INV-2025/003073','2025-09-08 14:35:29','2025-09-08',NULL,3,1190.00,119.00,1309.00,0.00,2,'cbe579703f9a2640a092fa251200c992',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1184,1,'2025-09-08 15:02:49',112,NULL,3072,'INV-',2,'INV-2025/003072','2025-09-08 14:37:19','2025-09-08',NULL,3,790.00,79.00,869.00,0.00,2,'ac0dde84e417e4446dcabeecc2f4f764',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1185,1,'2025-09-08 15:02:23',112,NULL,3071,'INV-',2,'INV-2025/003071','2025-09-08 14:40:40','2025-09-08',NULL,3,790.00,79.00,869.00,0.00,2,'34fbfbe0422942c254bc583f6e928ef7',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1186,1,'2025-09-08 15:01:31',112,NULL,3070,'INV-',2,'INV-2025/003070','2025-09-08 14:43:04','2025-09-08',NULL,3,220.00,22.00,242.00,0.00,2,'d8b89a8c262218d098fc97f754db3e49',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1187,1,'2025-09-08 15:00:46',112,NULL,3069,'INV-',2,'INV-2025/003069','2025-09-08 14:45:20','2025-09-08',NULL,3,790.00,79.00,869.00,0.00,2,'16b88ab173cdcb14da2232a849234d0a',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1188,1,'2025-09-08 15:00:25',112,NULL,3068,'INV-',2,'INV-2025/003068','2025-09-08 14:56:46','2025-09-08',NULL,3,1572.39,157.24,1729.63,0.00,2,'8a64cabee130878f0f7b1f7c730f42a8',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1189,0,NULL,449,NULL,3075,'INV-',2,'INV-2025/003075','2025-09-16 09:28:04','2025-09-16','2025-09-16',3,50665.32,5066.53,55731.85,0.00,2,'d7c0a08bab85e54001a9fea29b35ac52',3,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'161 Racecourse Rd, Redesdale VIC.','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1190,1,'2025-09-30 18:29:46',112,NULL,3076,'INV-',2,'INV-2025/003076','2025-09-30 18:28:12','2025-09-30',NULL,3,220.00,22.00,242.00,0.00,2,'cbafd3ece4e1943f3d208212b7be016a',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1191,1,'2025-09-30 18:33:05',112,NULL,3077,'INV-',2,'INV-2025/003077','2025-09-30 18:32:43','2025-09-30',NULL,3,790.00,79.00,869.00,0.00,2,'a5be6d8b0bb5ad2db8f4b04ded316581',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1192,1,'2025-09-30 18:36:25',112,NULL,3078,'INV-',2,'INV-2025/003078','2025-09-30 18:36:01','2025-09-30',NULL,3,790.00,79.00,869.00,0.00,2,'0f52d95dd77f8e1fff5377b65b1ea1fe',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1193,1,'2025-09-30 18:40:38',112,NULL,3079,'INV-',2,'INV-2025/003079','2025-09-30 18:40:15','2025-09-30',NULL,3,790.00,79.00,869.00,0.00,2,'45b5dd66f206b20f2581038fe43270c5',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1194,1,'2025-09-30 18:44:27',112,NULL,3080,'INV-',2,'INV-2025/003080','2025-09-30 18:44:08','2025-09-30',NULL,3,1345.12,134.51,1479.63,0.00,2,'ef4e0dde810ffa86b09da8eff3500977',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1195,1,'2025-09-30 19:22:47',450,NULL,3081,'INV-',2,'INV-2025/003081','2025-09-30 19:22:29','2025-09-30',NULL,3,550.00,55.00,605.00,0.00,2,'94281ac6fcf1e93b368a9f2b9590026d',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'','','','',NULL,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1196,1,'2025-10-08 18:09:44',9,NULL,3082,'INV-',2,'INV-2025/003082','2025-10-08 14:02:48','2025-10-08',NULL,3,3021.48,302.15,3323.63,0.00,2,'edeaaf7197739f1587c0321c5f85cd62',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Terms: Net 7 Days<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nAll materials supplied or installed by Veeken Plumbing Services Pty<br />\r\nLtd remain the property of Veeken Plumbing Services Pty Ltd until<br />\r\nfinal payment has been made.<br />\r\nThis is a payment claim made under the Building and Construction<br />\r\nIndustry Security of Payment Act 2002 Victoria.<br />\r\nPenalty rates will be applied after 7 days in accordance with Section 2 of the Penalty Interest Rate<br />\r\nAct 1983 at 9.5% per annum<br />\r\nDebt recovery charges will be levied against this account if payment is not received within 7 days.',0,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1197,1,'2025-10-08 18:09:57',9,NULL,3083,'INV-',2,'INV-2025/003083','2025-10-08 16:02:21','2025-10-08',NULL,3,4828.41,482.84,5311.25,0.00,2,'d26afec847bdcffe46e582ac5946c3c3',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1198,1,'2025-10-08 18:10:11',9,NULL,3084,'INV-',2,'INV-2025/003084','2025-10-08 16:10:39','2025-10-08',NULL,3,331.54,33.15,364.69,0.00,2,'feee07fd51dffeb1b6dd4ec6dfda5007',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',NULL,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1199,1,'2025-10-08 18:10:21',9,NULL,3085,'INV-',2,'INV-2025/003085','2025-10-08 16:16:07','2025-10-08',NULL,3,859.28,85.93,945.21,0.00,2,'ed6de09543360c010b01605b6fffa138',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',NULL,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1200,1,'2025-10-08 18:10:33',9,NULL,3086,'INV-',2,'INV-2025/003086','2025-10-08 16:27:50','2025-10-08',NULL,3,2528.13,252.81,2780.94,0.00,2,'8f0b4c21bddc18e2c035797fd70251a0',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',NULL,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1201,1,'2025-10-08 18:10:40',9,NULL,3087,'INV-',2,'INV-2025/003087','2025-10-08 16:31:15','2025-10-08',NULL,3,508.00,50.80,558.80,0.00,2,'b034fd073868ddc32c9b4ff0bff6de5f',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',NULL,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1202,1,'2025-10-08 18:10:50',9,NULL,3088,'INV-',2,'INV-2025/003088','2025-10-08 16:37:49','2025-10-08',NULL,3,1274.02,127.40,1401.42,0.00,2,'bfd0304a69af73a51d5adb8d81cc7831',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',NULL,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1203,1,'2025-10-08 18:10:59',9,NULL,3089,'INV-',2,'INV-2025/003089','2025-10-08 18:06:27','2025-10-08',NULL,3,23109.48,2310.95,25420.43,0.00,2,'564b9e725036074a058e899fda1b7cd1',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1204,0,NULL,451,NULL,3090,'INV-',2,'INV-2025/003090','2025-10-10 00:08:06','2025-10-10','2025-10-10',3,5990.06,676.01,6666.07,0.00,2,'571893505df034f9491181d4fe6ba7ab',4,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'699 Heckers Hill Way Kangaroo Ground','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1205,1,'2025-10-12 18:51:26',112,NULL,3091,'INV-',2,'INV-2025/003091','2025-10-12 18:36:31','2025-10-12',NULL,3,790.00,79.00,869.00,0.00,2,'4ad9508dee30884eba9b29701a95912f',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1206,1,'2025-10-17 17:40:16',449,NULL,3092,'INV-',2,'INV-2025/003092','2025-10-14 13:15:13','2025-10-14',NULL,3,5510.00,551.00,6061.00,0.00,2,'f039e66c4f9280c9d86c79811f8dfc28',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'161 Racecourse Rd, Redesdale VIC.','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1207,0,NULL,452,NULL,3093,'INV-',2,'INV-2025/003093','2025-10-18 15:00:43','2025-10-18','2025-10-18',3,4004.73,657.97,4662.70,0.00,2,'450289203d8f5f4faf581d3658f90676',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'24 Tolhurst Ave Boronia','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1208,1,'2025-11-07 11:54:58',454,NULL,3094,'INV-',2,'INV-2025/003094','2025-10-31 07:43:22','2025-10-31',NULL,3,5404.73,657.97,6062.70,0.00,2,'3d5ecae6dd764e05a29efbb61e56bf76',3,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'57 Rockys Way Lilydale','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1209,1,'2025-11-24 11:27:59',453,NULL,3095,'INV-',2,'INV-2025/003095','2025-11-05 21:06:02','2025-11-05','2025-11-05',3,11553.24,1283.32,12836.56,0.00,2,'013a082c508906e87e2d4222f7cbcb83',3,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'28 Callistemon Crescent Narre Warren','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1210,1,'2025-11-11 14:12:02',112,NULL,3096,'INV-',2,'INV-2025/003096','2025-11-09 18:36:58','2025-11-09',NULL,3,1790.00,179.00,1969.00,0.00,2,'7e48b1db171e768558f5fbd51d5141f5',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1211,1,'2025-11-11 14:12:33',112,NULL,3097,'INV-',2,'INV-2025/003097','2025-11-09 18:37:47','2025-11-09',NULL,3,250.00,25.00,275.00,0.00,2,'7c1d740a48436cd4161a98593ab62655',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1212,1,'2025-11-11 14:12:45',112,NULL,3098,'INV-',2,'INV-2025/003098','2025-11-09 18:41:32','2025-11-09',NULL,3,220.00,22.00,242.00,0.00,2,'f7f17f7b3d7ed11021aa30bf7c275f5f',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1213,1,'2025-11-11 14:13:02',112,NULL,3099,'INV-',2,'INV-2025/003099','2025-11-09 18:42:43','2025-11-09',NULL,3,790.00,79.00,869.00,0.00,2,'f02720887a6192df3f945b6da9884134',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1214,1,'2025-11-11 14:13:13',112,NULL,3100,'INV-',2,'INV-2025/003100','2025-11-09 18:43:30','2025-11-09',NULL,3,790.00,79.00,869.00,0.00,2,'18ac754788e9370159807209845fbe64',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1215,1,'2025-12-23 13:55:51',157,NULL,3101,'INV-',2,'INV-2025/003101','2025-11-09 18:44:55','2025-11-09',NULL,3,1300.00,130.00,1430.00,0.00,2,'ebc7278c3940db5abd6f8bfb2745fcf5',1,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'68 Victoria St<br />\r\nWARRAGUL VIC 3820<br />\r\nAUSTRALIA','','','',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1216,1,'2025-11-11 14:13:38',112,NULL,3102,'INV-',2,'INV-2025/003102','2025-11-09 18:45:28','2025-11-09',NULL,3,790.00,79.00,869.00,0.00,2,'4f7d5c157bf8f27418036c1d7199d79f',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1217,1,'2025-11-11 14:13:52',112,NULL,3103,'INV-',2,'INV-2025/003103','2025-11-09 18:45:57','2025-11-09',NULL,3,790.00,79.00,869.00,0.00,2,'49aa73aa80ab59cb6f5d03dfab8b5877',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1218,1,'2025-11-11 14:29:28',112,NULL,3104,'INV-',2,'INV-2025/003104','2025-11-11 14:23:44','2025-11-11',NULL,3,875.00,87.50,962.50,0.00,2,'78a6febe7b67bfb2a258405a4ad3f7e8',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'1/3 Nicole Close, Bayswater North','','Vic','3153',14,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1219,1,'2025-12-07 15:32:31',9,NULL,3105,'INV-',2,'INV-2025/003105','2025-11-15 14:31:24','2025-11-15',NULL,3,1482.00,148.20,1630.20,0.00,2,'4c986b7d15d60f7021ed123001415508',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,1,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1220,1,'2025-11-16 21:37:33',9,NULL,3106,'INV-',2,'INV-2025/003106','2025-11-16 21:02:13','2025-11-15',NULL,3,2302.97,230.30,2533.27,0.00,2,'f062571061967e0e0736b9ddb24f994e',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:1:{i:0;s:1:\"2\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1221,1,'2025-11-16 21:37:39',9,NULL,3107,'INV-',2,'INV-2025/003107','2025-11-16 21:05:15','2025-11-16',NULL,3,1409.35,140.94,1550.29,0.00,2,'63c4b933aef534904230b1e2666d8714',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1222,1,'2025-11-16 21:37:47',9,NULL,3108,'INV-',2,'INV-2025/003108','2025-11-16 21:15:50','2025-11-16',NULL,3,948.45,94.85,1043.30,0.00,2,'8582e0260597441ba6f3a1af52643bc5',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1223,1,'2025-11-16 21:37:57',9,NULL,3109,'INV-',2,'INV-2025/003109','2025-11-16 21:20:54','2025-11-16',NULL,3,1051.03,105.10,1156.13,0.00,2,'923a1c85d9428f45bfab41104fdfff4b',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1224,1,'2025-11-16 21:37:59',9,NULL,3110,'INV-',2,'INV-2025/003110','2025-11-16 21:24:05','2025-11-16',NULL,3,1303.29,130.33,1433.62,0.00,2,'79baef203a0410faa945e7a56d02b7b5',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),(1225,1,'2025-12-07 15:32:20',9,NULL,3111,'INV-',2,'INV-2025/003111','2025-11-16 21:24:46','2025-11-16',NULL,3,1303.29,130.33,1433.62,0.00,2,'2d4dab8c45ca89159a8ed2b7eeb50b34',2,'Thank you for choosing Veeken Plumbing, we look forward to working with you in the future.','',NULL,NULL,0,'a:2:{i:0;s:1:\"2\";i:1;s:6:\"stripe\";}',NULL,0.00,0.00,'',0,NULL,0,0,0,NULL,NULL,'Full terms and conditions apply see attached or visit https://www.veeken.plumbing/accounts/terms-and-conditions<br />\r\n<br />\r\nTerms: Payment is due on receipt unless otherwise agreed in writing<br />\r\nAccount Name: <br />\r\nVeeken Plumbing Services<br />\r\nBSB: 633 000<br />\r\nAcc No: 158 337 048<br />\r\n<br />\r\nTerms and Conditions of Engagement<br />\r\n<br />\r\nPrivacy and Legal Compliance<br />\r\nVeeken Plumbing Services Pty Ltd is committed to protecting client information. All personal and payment details provided will be handled securely and used only for the purposes of processing payments and managing accounts. Information will not be shared with third parties unless required by law or with client consent.<br />\r\nAll services provided by Veeken Plumbing Services Pty Ltd comply with Australian laws and regulations, including safety standards and industry guidelines.<br />\r\n<br />\r\nEnvironmental Considerations<br />\r\nVeeken Plumbing Services Pty Ltd is committed to environmentally responsible practices. This includes proper disposal of waste, recycling wherever possible, and using energy-efficient materials and methods in our projects.<br />\r\n<br />\r\nPayment Terms<br />\r\nVeeken Plumbing Services Pty Ltd is committed to ensuring clear and transparent payment terms for all clients, including builders, homeowners, commercial clients, and property managers. To maintain efficient operations and high-quality services, payment is required upfront or on the day of completion unless otherwise specified in writing.<br />\r\n<br />\r\nPayment Claim Notice<br />\r\nThis is a payment claim made under the Building and Construction Industry Security of Payment Act 2002 (Victoria). If payment is not received within seven (7) days of the due date, the following actions may be initiated:<br />\r\n1. Legal Action: Veeken Plumbing Services Pty Ltd reserves the right to take legal measures, including issuing a statutory demand or pursuing other recovery actions, to settle outstanding balances.<br />\r\n2. Debt Recovery Charges: Additional charges will be levied against accounts where payment is overdue. These may include, but are not limited to:<br />\r\n   - Administrative fees<br />\r\n   - Legal fees<br />\r\n   - Collection agency costs<br />\r\n3. Account-Keeping Fees: Overdue accounts will incur account-keeping fees. These fees are charged to cover the additional resources required to manage and maintain the account while it remains unpaid.<br />\r\nVeeken Plumbing Services Pty Ltd values prompt payment and appreciates your cooperation in adhering to the payment terms outlined in this policy.<br />\r\n<br />\r\nPayment Dispute Resolution<br />\r\nIn the event of a payment dispute, clients are required to submit written notice detailing the nature of the dispute within seven (7) days of receiving the invoice. Veeken Plumbing Services Pty Ltd will review the dispute and provide a response within 14 days. Both parties are encouraged to work collaboratively to resolve any issues promptly.<br />\r\n<br />\r\nNon-Payment Consequences Beyond Termination<br />\r\nIn addition to service termination, prolonged non-payment may result in reports to credit bureaus or legal actions to recover outstanding debts. Veeken Plumbing Services Pty Ltd reserves the right to pursue all available remedies under the law.<br />\r\n<br />\r\nAdditional Payment Guidelines for Commercial Clients and Property Managers<br />\r\nFor commercial clients and property managers, Veeken Plumbing Services Pty Ltd offers tailored invoicing and payment options to streamline transactions. However, the following terms apply:<br />\r\n1. Payment is expected upfront or on the day of completion for most services unless a prior arrangement is made in writing.<br />\r\n2. In cases of large-scale projects or ongoing maintenance agreements, progressive payment schedules can be arranged, with payments due at clearly defined milestones.<br />\r\n3. Any variation to the agreed-upon scope of work or services may result in additional charges, which will be invoiced separately and must be paid within the specified timeframe.<br />\r\n4. Work may be suspended if payment is not made as per the agreed terms.<br />\r\n<br />\r\nRefunds, Cancellations, and Special Orders<br />\r\nNearly all products and materials supplied by Veeken Plumbing Services Pty Ltd are classified as special order items. As such, they are non-returnable and non-refundable once ordered. Clients are responsible for confirming all specifications prior to approval.<br />\r\nRefunds or credits will only be issued under exceptional circumstances and at the sole discretion of Veeken Plumbing Services Pty Ltd. Any approved refunds will exclude restocking fees, supplier charges, or non-recoverable costs already incurred.<br />\r\nCancellations must be requested in writing and will be considered based on the stage of progress and order commitments. Any costs already incurred, including deposits or special orders, will be deducted from any potential refund.<br />\r\n<br />\r\nInspection and Acceptance<br />\r\nClients are required to inspect completed work within seven (7) days of completion. Any issues or defects must be reported in writing within this timeframe to be eligible for rectification under the applicable warranty.<br />\r\n<br />\r\nRetention of Title<br />\r\nAll materials and products supplied by Veeken Plumbing Services Pty Ltd remain the property of the company until full payment is received. Clients are encouraged to make prompt payments to ensure transfer of ownership.<br />\r\n<br />\r\nAccepted Payment Methods<br />\r\nVeeken Plumbing Services Pty Ltd accepts the following payment methods:<br />\r\n1. Bank Transfer / EFT (Electronic Funds Transfer)<br />\r\n2. Credit Card (a processing fee may apply)<br />\r\nClients are encouraged to confirm the preferred payment method in advance to avoid delays. For any questions regarding payment options, please contact our office directly.<br />\r\n<br />\r\nEarly Payment Discounts<br />\r\nVeeken Plumbing Services Pty Ltd offers an early payment discount of 2-5% for payments made in full prior to the commencement of services or within a shorter specified timeframe. This incentive encourages prompt settlement and streamlines the transaction process.<br />\r\n<br />\r\nTimeframe for Service Completion<br />\r\nWhile Veeken Plumbing Services Pty Ltd strives to complete all projects within the agreed timeframe, unforeseen circumstances such as delays in material supply or adverse weather conditions may extend the completion timeline. Clients will be informed of any expected delays as soon as possible.<br />\r\n<br />\r\nGoverning Law<br />\r\nThis policy is governed by and construed in accordance with the laws of Victoria, Australia. Any disputes arising under these terms will be resolved under the jurisdiction of the courts in Victoria.<br />\r\n<br />\r\nClient Responsibilities<br />\r\nClients are responsible for providing a clear and safe worksite to ensure that Veeken Plumbing Services Pty Ltd can perform services efficiently and safely. This includes:<br />\r\n1. Ensuring access to the worksite at agreed times.<br />\r\n2. Removing obstructions or hazards that may impede work.<br />\r\n3. Complying with any safety instructions provided by Veeken Plumbing Services Pty Ltd.<br />\r\nFailure to meet these responsibilities may result in additional costs being incurred to address delays, hazards, or obstructions that hinder the progress of the work. Veeken Plumbing Services Pty Ltd reserves the right to invoice for any additional time or resources required as a result of these issues.<br />\r\n<br />\r\nIndemnity Clause<br />\r\nClients agree to indemnify Veeken Plumbing Services Pty Ltd against any claims, damages, or losses resulting from incorrect information provided, unsafe conditions at the work site, or any actions that may hinder the successful completion of services.<br />\r\n<br />\r\nSeverability Clause<br />\r\nIf any provision of this policy is found to be invalid or unenforceable, the remaining provisions will remain in full force and effect.<br />\r\n<br />\r\nWarranty and Liability Terms<br />\r\nVeeken Plumbing Services Pty Ltd provides the following warranties to ensure quality and peace of mind:<br />\r\n1. Product Warranty: Products installed by Veeken Plumbing Services Pty Ltd typically come with a manufacturer’s warranty of up to five (5) years. Clients are encouraged to retain documentation for warranty claims.<br />\r\n2. Workmanship Warranty: All workmanship is covered by a warranty of six (6) years, ensuring that services provided meet professional standards and regulations.<br />\r\n3. Warranty Conditions: Warranties are contingent upon full payment of all outstanding balances. No warranty claims will be processed until accounts are paid in full.<br />\r\n4. Extended Warranties: Extended warranties may be available for products and workmanship if the systems or services are regularly maintained by Veeken Plumbing Services Pty Ltd under a service agreement. Contact our office for more details on eligibility and terms.<br />\r\n<br />\r\nStandard Site Conditions<br />\r\nAll quotes are based on standard site conditions. Any unforeseen issues, access limitations, or additional work required will be quoted and billed separately. Veeken Plumbing Services Pty Ltd will notify the client of any variations prior to proceeding with additional work.<br />\r\n<br />\r\nService Scope<br />\r\nVeeken Plumbing Services Pty Ltd will deliver services as outlined in the agreed-upon scope of work. In cases where a written scope is not provided or where the nature of the work is do-and-charge, services will be carried out as required based on site conditions, urgency, and professional judgment.<br />\r\nAny services outside a defined or reasonable scope may incur additional charges. While Veeken Plumbing Services Pty Ltd will endeavour to communicate variations where practicable, prior approval may not always be possible due to site conditions or urgency. Clients remain responsible for charges incurred in the course of necessary work.',2,'90 Alexandra Rd','Ringwood East','Vic','3135',0,NULL,NULL,NULL,NULL,NULL,0,1,1,0,0,NULL,NULL),